1.0 Definitions

1.3 "Guarantor” means that person (or persons), or entity, who agrees to be liable for the debts of the Client on a principal debtor basis.

1.4 “Goods” shall mean Goods supplied by the Contractor to the Client (and where the context so permits shall include any supply of Services as herein after defined) and are as described on the invoices, quotation, work authorisation or any other forms as provided by the Contractor to the Client.

1.5 “Services” shall mean all Services supplied by the "Contractor" to the "Client" and includes any advice or recommendations (and where the context so permits shall include any supply of Goods as defined above).

1.6 “Price” shall mean the price payable for the Goods as agreed between the Contractor and the Client in accordance with (clause 4) of this contract.

2.0 The Commonwealth Trade Practices Act 1974 (“TPA”) and Fair Trading Acts (“FTA”)

2.1 Nothing in this agreement is intended to have the effect of contracting out of any applicable provisions of the TPA or the FTA in each of the States and Territories of Australia, except to the extent permitted by those Acts where applicable.

3.0 Acceptance

3.1 Any instructions received by the Contractor from the Client for the supply of Goods and/or the Client’s acceptance of Goods supplied by the Contractor shall constitute acceptance of the terms and conditions contained herein.

3.2 Where more than one Client has entered into this agreement, the Clients shall be jointly and severally liable for all payments of the Price and or contacted agreement total including all variations and associated costs).

3.3 Upon acceptance of these terms and conditions by the Client the terms and conditions are binding and can only be amended with the written consent of the Contractor.

3.4 The Client shall give the Contractor not less than fourteen (14) days prior written notice of any proposed change of ownership of the Client or any change in the Client’s name and/or any other change in the Client’s details (including but not limited to, changes in the Client’s address, facsimile number, or business practice). The Client shall be liable for any loss incurred by the Contractor as a result of the Client’s failure to comply with this clause.

3.5 Goods are supplied by the Contractor only on the terms and conditions of trade herein to the exclusion of anything to the contrary in the terms of the Client’s order notwithstanding that any such order is placed on terms that reason to override these terms and conditions of trade.

4.0 Price And Payment

4.1 At the Contractors sole discretion the Price shall be either: (a) as indicated on invoices provided by the Contractor to the Client in respect of Goods supplied; or (b) the Contractors quoted Price (subject to clause 4.2) which shall be binding upon the Contractor provided that the Client shall accept the Contractors quotation in writing within thirty (30) days.

4.2 The Contractor reserves the right to change the Price in the event of a variation to the Contractors quotation. Any variation from the plan of scheduled works or specifications (including, but not limited to, any variation due to unforeseen circumstances, or as a result of increases to the Contractor in the cost of materials and labour) will be charged for on the basis of the Contractors quotation and will be shown as variation/s on the invoice. Payment for all variations must be made in full at their time of completion.

4.3 The Contractor may submit a detailed payment claim at intervals not less than one week for work performed up to the end of each week. The value of work so performed shall include the reasonable value of authorised variations and the value of materials delivered to the site but not yet installed.

4.4 At the Contractors sole discretion a non-refundable deposit may be required.

4.5 At the Contractors sole discretion (a) payment shall be due on delivery of the Goods; or (b) payment shall be due before delivery of the Goods; or (c) payment for approved Clients shall be made by instalments in accordance with the Contractors payment schedule. 4.6 Time for payment for the Goods shall be of the essence and will be stated on the invoice or any other forms. If no time is stated then payment shall be due one (1) day following the date of the invoice.

4.7 Payment will be made by cash, or by cheque, or by bank cheque, or by credit card (plus a surcharge of up to five percent (5%) of the Price), or by direct deposit, or by any other method as agreed to between the Client and the 'Contractor'.

4.8 GST and other taxes and duties that may be applicable shall be added to the Price except when they are expressly included in the Price.

5.0 Delivery Of Goods

5.1 At the Contractors sole discretion delivery of the Goods shall take place when: (a) the Client takes possession of the Goods at the Client’s nominated address (in the event that the Goods are delivered by the Contractor or the Contractors nominated carrier); or (b) the Client’s nominated carrier takes possession of the Goods in which event the carrier shall be deemed to be the Client’s agent.

5.2 At the Contractors sole discretion the costs of delivery are (a) included in the Price; or (b) in addition to the Price; or (c) or the Client’s account.

5.3 The Client shall make all arrangements necessary to take delivery of the Goods whenever they are tendered for delivery. In the event that the Client is unable to take delivery of the Goods as arranged then the Contractor shall be entitled to charge a reasonable fee for re-delivery.

5.4 Delivery of the Goods to a third party nominated by the Client is deemed to be delivery to the Client for the purposes of this agreement.

5.5 The Contractor may deliver the Goods by separate instalments. Each separate instalment shall be invoiced and paid in accordance with the provisions of these terms and conditions.

5.6 The Client shall take delivery of the Goods tendered notwithstanding that the quantity so delivered shall be either greater or lesser than the quantity purchased provided that:(a) such discrepancy in quantity shall not exceed five percent (5%); and (b) the Price shall be adjusted pro rata to the discrepancy.

5.7 The failure of the Contractor to deliver shall not entitle either party to treat this contract as repudiated.

5.8 The Contractor shall not be liable for any loss or damage whatsoever due to failure by the Contractor to deliver the Goods (or any of them) promptly or at all, where due to circumstances beyond the control of the Contractor.

6.0 Risk

6.1 If the Contractor retains ownership of the Goods nonetheless, all risk for the Goods passes to the Client on delivery.

6.2 If any of the Goods are damaged or destroyed following delivery but prior to ownership passing to the Client, the Contractor is entitled to receive all insurance proceeds payable for the Goods. The production of these terms and conditions by the Contractor is sufficient evidence of the Contractors rights to receive the insurance proceeds without the need for any person dealing with the Contractor to make further enquiries.

6.3 Where the Client expressly requests the Contractor to leave Goods outside the Contractors premises for collection or to deliver the Goods to an unattended location then such Goods shall be left at the Client’s sole risk and it shall be the Client’s responsibility to ensure the Goods are insured adequately or at all.

6.4 Timber is a natural product and as such colour, shade tone, markings, and veining may vary from samples provided. Whilst the Contractor will make every effort to match sales samples to the finished Goods the Contractor accepts no liability whatsoever where the samples differ to the finished Goods.

6.5 Timber is a hydroscopic material subject to expansion and contraction, therefore the Contractor will accept no responsibility for gaps that may appear in the flooring during prolonged dry periods. 6.6 The Client acknowledges that Goods supplied may: (a) exhibit variations in shade, colour, texture, surface, finish, markings and may contain natural fissures, occlusions, lines, indentations and may fade or change colour over time; and (b) expand, contract or distort as a result of exposure to heat, cold, weather; and (c) mark or stain if exposed to certain substances; and (d) be damaged or disfigured by impact or scratching.

7.0 Access

7.1 The Client shall ensure that the Contractor has clear and free access to the work site at all times to enable them to undertake the works. The Contractor shall not be liable for any loss or damage to the site (including, without limitation, damage to pathways, driveways and concreted or paved or grassed areas) unless due to the negligence of the Contractor.

8.0 Underground Locations

8.1 Prior to the Contractor commencing any work the Client must advise the Contractor of the precise location of all underground services on the site and clearly mark the same. The underground mains & services the Client must identify include, but are not limited to, electrical services, gas services, sewer services, pumping services, sewer connections, sewer sludge mains, water mains, irrigation pipes, telephone cables, fibre optic cables, oil pumping mains, and any other services that may be on site.

8.2 Whilst the Contractor will take all care to avoid damage to any underground services the Client agrees to indemnify the Contractor in respect of all and any liability claims, loss, damage, costs and fines as a result of damage to services not precisely located and notified as per clause 8.1.

9.0 Title

9.1 The Contractor and the Client agree that ownership of the Goods shall not pass until: (a) the Client has paid the Contractor all amounts owing for the particular Goods; and (b) the Client has met all other obligations due by the Client to the Contractor in respect of all contracts between the Contractor and the Client.

9.2 Receipt by the Contractor of any form of payment other than cash shall not be deemed to be payment until that form of payment has been honoured, cleared or recognised and until then the Contractor's ownership or rights in respect of the Goods shall continue.

9.3 It is further agreed that: (a) where practicable the Goods shall be kept separate and identifiable until the Contractor shall have received payment and all other obligations of the Client are met; and (b) until such time as ownership of the Goods shall pass from the Contractor to the Client the Contractor may give notice in writing to the Client to return the Goods or any of them to the Contractor. Upon such notice the rights of the Client to obtain ownership or any other interest in the Goods shall cease; and (c) the Contractor shall have the right of stopping the Goods in transit whether or not delivery has been made; and (d) if the Client fails to return the Goods to the Contractor then the Contractor or the Contractors agent may enter upon and into land and premises owned, occupied or used by the Client, or any premises as the invitee of the Client, where the Goods are situated and take possession of the Goods; and (e) the Client is only a bailee of the Goods and until such time as the Contractor has received payment in full for the Goods then the Client shall hold any proceeds from the sale or disposal of the Goods, up to and including the amount the Client owes to the Contractor for the Goods, on trust for the Contractor; and (f) the Client shall not deal with the money of the Contractor in any way which may be adverse to the Contractor; and (g) the Client shall not charge the Goods in any way nor grant nor otherwise give any interest in the Goods while they remain the property of the Contractor; and (h) the Contractor can issue proceedings to recover the Price of the Goods sold notwithstanding that ownership of the Goods may not have passed to the Client; and (i) until such time that ownership in the Goods passes to the Client, if the Goods are converted into other products, the parties agree that the Contractor will be the owner of the end products.

10.0 Defects

10.1 The Client shall inspect the Goods on delivery and shall within five (5) days of delivery (time being of the essence) notify the Contractor of any alleged defect, shortage in quantity, damage or failure to comply with the description or quote. The Client shall afford the Contractor an opportunity to inspect the Goods within a reasonable time following delivery if the Client believes the Goods are defective in any way. If the Client shall fail to comply with these

provisions the Goods shall be presumed to be free from any defect or damage. For defective Goods, which the Contractor has agreed in writing that the Client is entitled to reject, the Contractor’s liability is limited to either (at the Contractor’s discretion) replacing the Goods or repairing the Goods except where the Client has acquired Goods as a consumer within the meaning of the Trade Practices Act 1974 (CWlth) or the Fair Trading Acts of the relevant state or territories of Australia, and is therefore also entitled to, at the consumer’s discretion either a refund of the purchase price of the Goods, or repair of the Goods, or replacement of the Goods.

10.2 Goods will not be accepted for return other than in accordance with 10.1 above.

11.0 Warranty

11.1 Subject to the conditions of warranty set out in clause 11.2 the Contractor warrants that if any defect in any workmanship of the Contractor becomes apparent and is reported to the Contractor within thirty six (36) months of the date of delivery (time being of the essence) then the Contractor will either (at the Contractors sole discretion) replace or remedy the workmanship.

11.2 The conditions applicable to the warranty given by clause 11.1 are: (a) the warranty shall not cover any defect or damage which may be caused or partly caused by or arise through: (i) failure on the part of the Client to properly maintain any Goods; or (ii) failure on the part of the Client to follow any instructions or guidelines provided by the Contractor; or (iii) any use of any Goods otherwise than for any application specified on a quote or order form; or (iv) the continued use of any Goods after any defect becomes apparent or would have become to a reasonably prudent operator or user; or (v) fair wear and tear, any accident or act of God. (b) the warranty shall cease and the Contractor shall thereafter in no circumstances be liable under the terms of the warranty if the workmanship is repaired, altered or overhauled without the Contractor's consent. (c) in respect of all claims the Contractor shall not be liable to compensate the Client for any delay in either replacing or remedying the workmanship or in properly assessing the Client’s claim.

11.3 For Goods not manufactured by the Contractor, the warranty shall be the current warranty provided by the manufacturer of the Goods. The Contractor shall not be bound by nor be responsible for any term, condition, representation or warranty other than that which is given by the manufacturer of the Goods.

12.0 Intellectual Property

12.1 Where the Contractor has designed, drawn or written Goods for the Client, then the copyright in those designs and drawings and documents shall remain vested in the Contractor, and shall only be used by the Client at the Contractors discretion.

12.2 The Client warrants that all designs or instructions to the Contractor will not cause the Contractor to infringe any patent, registered design or trademark in the execution of the Client’s order and the Client agrees to indemnify the Contractor against any action taken by a third party against the Contractor in respect of any such infringement.

12.3 The Client hereby authorises the Contractor to utilise images of the Goods designed or drawn by the Contractor in advertising, marketing, or competition material by the Contractor.

13.0 Default & Consequences of Default

13.1 Interest on overdue invoices shall accrue daily from the date when payment becomes due, until the date of payment, at a rate of two and one half percent (2.5%) per calendar month (and at the Contractors sole discretion such interest shall compound monthly at such a rate) after as well as before any judgment.

13.2 In the event that the Client’s payment is dishonoured for any reason the Client shall be liable for any dishonour fees incurred by the Contractor.

13.3 If the Client defaults in payment of any invoice when due, the Client shall indemnify the Contractor from and against all costs and disbursements incurred by the Contractor in pursuing the debt including legal costs on a solicitor and own client basis and the Contractors collection agency costs.

13.4 Without prejudice to any other remedies the Contractor may have, if at any time the Client is in breach of any obligation (including those relating to payment) the Contractor may suspend or terminate the supply of Goods to the Client and any of its other obligations under the terms and conditions. The Contractor will not be liable to the Client for any loss or damage the Client suffers because the Contractor has exercised its rights under this clause.

13.5 If any account remains overdue after thirty (30) days then an amount of the greater of fifty dollars ($50.00) or five percent (5%) of the amount overdue (up to a maximum of two hundred and fifty.

dollars ($250.00)) shall be levied for administration fees which sum shall become immediately due and payable.

13.6 Without prejudice to the Contractors other remedies by law the Contractor shall be entitled to cancel all or any part of any order of the Client which remains unfulfilled and all amounts owing to the Contractor shall, whether or not due for payment, become immediately payable in the event that: (a) any money payable to the Contractor becomes overdue, or in the Contractors opinion the Client will be unable to meet its payments as they fall due; or (b) the Client becomes insolvent, convenes a meeting with its creditors or proposes or enters into an arrangement with creditors, or makes an assignment for the benefit of its creditors; or (c) a receiver, manager, liquidator (provisional or otherwise) or similar person is appointed in respect of the Client or any asset of the Client.

14.0 Security And Charge

14.1 Despite anything to the contrary contained herein or any other rights which the Contractor may have howsoever: (a) where the Client and/or the Guarantor (if any) is the owner of land, realty or any other asset capable of being charged, both the Client and/or the Guarantor agree to mortgage and/or charge all of their joint and/or several interest in the said land, realty or any other asset to the Contractor or the Contractors nominee to secure all amounts and other monetary obligations payable under these terms and conditions. The Client and/or the Guarantor acknowledge and agree that the Contractor (or the Contractors nominee) shall be entitled to lodge where appropriate a caveat, which caveat shall be withdrawn once all payments and other monetary obligations payable hereunder have been met.

(b) should the Contractor elect to proceed in any manner in accordance with this clause and/or its sub-clauses, the Client and/or Guarantor shall indemnify the Contractor from and against all the Contractors costs and disbursements including legal costs on a solicitor and own client basis.

(c) the Client and/or the Guarantor (if any) agree to irrevocably nominate constitute and appoint the Contractor or the Contractors nominee as the Client’s and/or Guarantor’s true and lawful attorney to perform all necessary acts to give effect to the provisions of this clause 14.1.

15.0 Compliance with Laws

15.1 The Client and the Contractor shall comply with the provisions of all statutes, regulations and bylaws of government, local and other public authorities that may be applicable to the works.

15.2 The Client shall obtain (at the expense of the Client) all licenses and approvals that may be required for the works.

15.3 The Client agrees that the site will comply with any occupational health and safety laws relating to building and or construction sites and any other relevant safety standards or legislation.

16.0 Cancellation

16.1 The Contractor may cancel any contract to which these terms and conditions apply or cancel delivery of Goods at any time before the Goods are delivered by giving written notice to the Client. On giving such notice the Contractor shall repay to the Client any sums paid in respect of the Price. The Contractor shall not be liable for any loss or damage whatsoever arising from such cancellation. 16.2 In the event that the Client cancels delivery of Goods the Client shall be liable for any loss incurred by the Contractor (including, but not limited to, any loss of profits) up to the time of cancellation.

16.3 Cancellation of orders for Goods made to the Client’s specifications or non-stocklist items will definitely not be accepted, once production has commenced.

17.0 Privacy Act 1988

17.1 The Client and/or the Guarantor/s agree for the Contractor to obtain from a credit reporting agency a credit report containing personal credit information about the Client and Guarantor/s in relation to credit provided by the Contractor.

17.2 The Client and/or the Guarantor/s agree that the Contractor may exchange information about the Client and the Guarantor/s with those credit providers either named as trade referees by the Client or named in a consumer credit report issued by a credit reporting agency for the following purposes: (a) to assess an application by Client; and/or (b) to notify other credit providers of a default by the Client; and/or (c) to exchange information with other credit providers as to the status of this credit account, where the Client is in default with other credit providers; and/or (d) to assess the credit worthiness of Client and/or Guarantor/s.

17.3 The Client consents to the Contractor being given a consumer credit report to collect overdue payment on commercial credit (Section 18K(1)(h) Privacy Act 1988).

17.4 The Client agrees that personal credit information provided may be used and retained by the Contractor for the following purposes and for other purposes as shall be agreed between the Client and Contractor or required by law from time to time: (a) provision of Goods; and/or (b) marketing of Goods by the Contractor, its agents or distributors in relation to the Goods; and/or (c) analysing, verifying and/or checking the Client’s credit, payment and/or status in relation to provision of Goods; and/or (d) processing of any payment instructions, direct debit facilities and/or credit facilities requested by Client; and/or (e) enabling the daily operation of Client’s account and/or the collection of amounts outstanding in the Client’s account in relation to the Goods.

17.5 The Contractor may give information about the Client to a credit reporting agency for the following purposes: (a) to obtain a consumer credit report about the Client; and/or (b) allow the credit reporting agency to create or maintain a credit information file containing information about the Client.

18.0 Building and Construction Industry Payments Act 2004

18.1 At the Contractors sole discretion, if there are any disputes or claims for unpaid Goods and/or Services then the provisions of the Building and Construction Industry Payments Act 2004 may apply. 18.2 Nothing in this agreement is intended to have the affect of contracting out of any applicable provisions of the Building and Construction Industry Payments Act 2004 of Queensland, except to the extent permitted by the Act where applicable.

19.0 General

19.1 If any provision of these terms and conditions shall be invalid, void, illegal or unenforceable the validity, existence, legality and enforceability of the remaining provisions shall not be affected, prejudiced or impaired.

19.2 These terms and conditions and any contract to which they apply shall be governed by the laws of the State of which it is used and are subject to the jurisdiction of the courts of that state.

19.3 The Contractor shall be under no liability whatsoever to the Client for any indirect and/or consequential loss and/or expense (including loss of profit) suffered by the Client arising out of a breach by the Contractor of these terms and conditions.

19.4 In the event of any breach of this contract by the Contractor the remedies of the Client shall be limited to damages which under no circumstances shall exceed the Price of the Goods.

19.5 The Client shall not be entitled to set off against, or deduct from the Price, any sums owed or claimed to be owed to the Client by the Contractor nor to withhold payment of any invoice because part of that invoice is in dispute.

19.6 The Contractor may license or sub-contract all or any part of its rights and obligations without the Client’s consent.

19.7 The Client agrees that the Contractor may review these terms and conditions at any time. If, following any such review, there is to be any change to these terms and conditions, then that change will take effect from the date on which the Contractor notifies the Client of such change.

19.8 Neither party shall be liable for any default due to any act of God, war, terrorism, strike, lock-out, industrial action, fire, flood, storm or other event beyond the reasonable control of either party.

19.9 The failure by the Contractor to enforce any provision of these terms and conditions shall not be treated as a waiver of that provision, nor shall it affect the Contractors right to subsequently enforce that provision.

20.0 Signatory and Initialling

20.1 The signing of a document by signature (and or) initialling represents that the Client/s (and or) Contractor have sighted, understood and agree to all the information (not limited to) specifications, terms, costs, price/s and any other details mentioned within the document, form (and or) page. All documentation and pages must have the Owners initials at the the bottom right hand corner of each page and the original copy/s must be forwarded back to the Contractor to proceed. A single signature on any documentation by the from the contractor will represent a combined approval from the other client (if applicable).

www.GCMarine.com.au / Info@GCMarine.com.au